[*]: THE IDENTIFIED INFORMATION HAS BEEN OMITTED FROM THE AGREEMENT BECAUSE IT IS BOTH (i) NOT MATERIAL AND (ii) WOULD BE COMPETITIVELY HARMFUL IF PUBLICLY DISCLOSED
Dated 17 June 2021
LEONARDO TWO, LTD.
as Borrower
and
NCL CORPORATION LTD.
as Guarantor
and
NCL INTERNATIONAL, LTD.
as Shareholder
and
NORWEGIAN CRUISE LINE HOLDINGS LTD.
as the Holding
and
THE Banks and FINANCIAL INSTITUTIONS listed IN Schedule 1
as Lenders
and
CRÉDIT AGRICOLE CORPORATE AND INVESTMENT BANK
BNP PARIBAS FORTIS S.A./N.V.
HSBC BANK PLC
CASSA DEPOSITI E PRESTITI S.P.A.
as Joint Mandated Lead Arrangers
and
CRÉDIT AGRICOLE CORPORATE AND INVESTMENT BANK
as Agent
and SACE Agent
and
CRÉDIT AGRICOLE CORPORATE AND INVESTMENT BANK
as Security Trustee
AMENDMENT AND RESTATEMENT AGREEMENT
relating to a facility agreement originally dated 12 April 2017
(as amended and restated by an amendment and restatement agreement dated 21 November 2017,
as amended by a supplemental agreement dated 4 June 2020 and as amended and restated by an amendment and restatement agreement dated 17 February 2021)
in respect of the part financing of the 3,300 passenger cruise ship newbuilding
presently designated as Hull No. [*] at Fincantieri S.p.A
Index
Schedules
Execution
Appendices
Form of Amended and Restated Facility Agreement (marked to indicate amendments)
THIS AGREEMENT is made on 17 June 2021
(1) | LEONARDO TWO, LTD., an exempted company incorporated under the laws of Bermuda whose registered office is at Park Place, 55 Par-la-Ville Road, Hamilton HM11, Bermuda as borrower (the "Borrower") |
(2) | NCL CORPORATION LTD., an exempted company incorporated under the laws of Bermuda with its registered office at Park Place, 55 Par-la-Ville Road, Hamilton HM11, Bermuda (the "Guarantor") |
(3) | NCL INTERNATIONAL, LTD., a company incorporated under the laws of Bermuda and having its registered office at Park Place, 55 Par-la-Ville Road, Hamilton HM11, Bermuda (the "Shareholder") |
(4) | NORWEGIAN CRUISE LINE HOLDINGS LTD., a company incorporated under the laws of Bermuda with its registered office at Park Place, 55 Par-la-Ville Road, Hamilton HM11, Bermuda (the "Holding") |
(5) | THE FINANCIAL INSTITUTIONS listed in Schedule 1(The Lenders) as lenders (the "Lenders") |
1 | Definitions and Interpretation |
1.1 | Definitions |
In this Agreement:
"Effective Date" means the date on which the Agent notifies the Borrower, the other Creditor Parties, SACE and SIMEST as to the satisfaction of the conditions precedent as provided in paragraph (a) of Clause 2.1 (Conditions Precedent and Conditions Subsequent).
"Obligors" means the Borrower, the Guarantor, the Holding and the Shareholder.
2
(b) | the improvements, changes and modifications agreed between the Borrower (as Owner under the Shipbuilding Contract) and the Builder, pursuant to article 9.2 of the Shipbuilding Contract. |
1.2 | Defined expressions |
Defined expressions in the Facility Agreement and, with effect from the Effective Date, the Amended and Restated Facility Agreement, shall have the same meanings when used in this Agreement unless the context otherwise requires or unless otherwise defined in this Agreement.
1.3 | Application of construction and interpretation provisions of Facility Agreement |
Clause 1.2 (Construction of certain terms) of the Facility Agreement applies to this Agreement as if it were expressly incorporated in it with any necessary modifications.
1.4 | Designation as a Finance Document |
The Borrower and the Agent designate this Agreement as a Finance Document.
3
1.5 | Third party rights |
(b) | Notwithstanding any term of any Finance Document, the consent of any person who is not a Party (other than SACE and SIMEST) is not required to rescind or vary this Agreement at any time. |
2 | Conditions Precedent and Conditions Subsequent |
2.1 | The Effective Date cannot occur unless: |
(d) | the Agent is satisfied that the Effective Date can occur and has not provided any instructions to the contrary informing the Parties that the Effective Date cannot occur. |
4
3 | Representations |
3.1 | Facility Agreement representations |
On the date of this Agreement and on the Effective Date, each Obligor that is a party to the Facility Agreement makes each of the representations and warranties as set out in clause 11 (Representations and warranties) of the Facility Agreement, as amended and restated by this Agreement and updated with appropriate modifications to refer to this Agreement and (where relevant) the Amended and Restated Facility Agreement, by reference to the circumstances then existing.
3.2 | Finance Document representations |
On the date of this Agreement and on the Effective Date, each Obligor (save for the Holding) makes the representations and warranties set out in the Finance Documents (other than the Facility Agreement) to which it is a party, as amended and restated and/or supplemented by this Agreement and updated with appropriate modifications to refer to this Agreement, by reference to the circumstances then existing.
4 | Amendment and Restatement of Facility Agreement and other Finance Documents |
4.1 | Specific amendments to the Facility Agreement |
With effect on and from the Effective Date, the Facility Agreement shall be amended and restated in the form of the Amended and Restated Facility Agreement and, as so amended and restated, the Facility Agreement shall continue to be binding on each of the parties to it in accordance with its terms as so amended and restated.
4.2 | Confirmation of Guarantee |
With effect on and from the Effective Date the Guarantor confirms that:
(a) | the Guarantee extends to the obligations of the Borrower under the Finance Documents as amended, restated and/or supplemented by this Agreement; |
4.3 | Security Confirmation |
5
(c) | the Security Interests created under the Finance Documents continue in full force and effect on the terms of the respective Finance Documents; and |
(d) | to the extent that this confirmation creates a new Security Interest, such Security Interest shall be on the terms of the Finance Documents in respect of which this confirmation is given. |
4.4 | Finance Documents to remain in full force and effect |
The Finance Documents shall remain in full force and effect and, from the Effective Date:
(a) | in the case of the Facility Agreement as amended and restated pursuant to Clause 4.1 (Specific amendments to the Facility Agreement); |
(b) | the Facility Agreement and the applicable provisions of this Agreement will be read and construed as one document; and |
5 | Further Assurance |
Clause 12.20 (Further assurance) of the Facility Agreement, as amended and restated by this Agreement, applies to this Agreement as if it were expressly incorporated in it with any necessary modifications.
6 | Costs, Expenses and Fees |
6.2 | The Borrower shall pay to each of (i) the Agent for its own account and (ii) the Agent (for the account of each Lender) such fees in the amount and at the times specified in the relevant June 2021 Fee Letters. |
7 | Notices |
Clause 32 (Notices) of the Facility Agreement, as amended and restated by this Agreement, applies to this Agreement as if it were expressly incorporated in it with any necessary modifications.
6
8 | Counterparts |
This Agreement may be executed in any number of counterparts, and this has the same effect as if the signatures on the counterparts were on a single copy of this Agreement.
9 | Signing Electronically |
The Parties acknowledge and agree that they may execute this Agreement and any variation or amendment to the same, by electronic instrument. The Parties agree that the electronic signatures appearing on the documents shall have the same effect as handwritten signatures and the use of an electronic signature on this Agreement shall have the same validity and legal effect as the use of a signature affixed by hand and is made with the intention of authenticating this Agreement, and evidencing the Parties' intention to be bound by the terms and conditions contained herein. For the purposes of using an electronic signature, the Parties authorise each other to conduct the lawful processing of personal data of the signers for contract performance and their legitimate interests including contract management.
10 | Governing Law |
This Agreement and any non-contractual obligations arising out of or in connection with it are governed by English law.
11 | Enforcement |
11.1 | Jurisdiction |
(a) | The courts of England have exclusive jurisdiction to settle any dispute arising out of or in connection with this Agreement (including a dispute regarding the existence, validity or termination of this Agreement or any non-contractual obligation arising out of or in connection with this Agreement) (a "Dispute"). |
(b) | The Obligors accept that the courts of England are the most appropriate and convenient courts to settle Disputes and accordingly no Obligor will argue to the contrary. |
11.2 | Service of process |
(a) | Without prejudice to any other mode of service allowed under any relevant law, each Obligor (other than an Obligor incorporated in England and Wales): |
(ii) | agrees that failure by a process agent to notify the relevant Obligor of the process will not invalidate the proceedings concerned. |
(b) | If any person appointed as an agent for service of process is unable for any reason to act as agent for service of process, the Borrower (on behalf of all the Obligors) must immediately (and in any event within 10 days of such event taking place) appoint another agent on terms acceptable to the Agent. Failing this, the Agent may appoint another agent for this purpose. |
This Agreement has been entered into on the date stated at the beginning of this Agreement.
7
Leonardo Two
Amendment and Restatement Agreement
BORROWER
SIGNED by) /s/ Daniel S. Farkas
duly authorised) Daniel S. Farkas
for and on behalf of)
LEONARDO TWO, LTD. )
GUARANTOR
SIGNED by) /s/ Daniel S. Farkas
duly authorised) Daniel S. Farkas
for and on behalf of)
NCL CORPORATION LTD. )
SHAREHOLDER
SIGNED by) /s/ Daniel S. Farkas
for and on behalf of) Daniel S. Farkas
NCL INTERNATIONAL, LTD.)
as its duly appointed attorney-in-fact)
in the presence of:) /s/ Jared G. Silberhorn
) Jared G. Silberhorn
) 7665 Corporate Center Drive
) Miami, FL 33126 USA
HOLDING
SIGNED by) /s/ Daniel S. Farkas
for and on behalf of) Daniel S. Farkas
NORWEGIAN CRUISE LINE)
HOLDINGS LTD.)
as its duly appointed attorney-in-fact)
in the presence of:) /s/ Jared G. Silberhorn
) Jared G. Silberhorn
) 7665 Corporate Center Drive
) Miami, FL 33126 USA
Leonardo Two
Amendment and Restatement Agreement
LENDERS
SIGNED by ) /s/ Cosmo Fisher
duly authorised ) Cosmo Fisher
for and on behalf of) Attorney-in-Fact
AND INVESTMENT BANK )
SIGNED by ) /s/ Bruno Cloquet
duly authorised ) Bruno Cloquet
for and on behalf of)Global Head of Exporters and ECAs Origination
BNP PARIBAS FORTIS S.A./N.V )
) /s/ Michel Froidebise
)Michel Froidebise
)Head of Export Finance Nordic Origination
SIGNED by ) /s/ Alessandro Mazzi
duly authorised ) Alessandro Mazzi
for and on behalf of) MD — Head of Export and Asset Finance, Italy
HSBC CONTINENTAL EUROPE, ITALY)
SIGNED by ) /s/ Isabella Roberts
duly authorised ) Isabella Roberts
for and on behalf of) Attorney-in-Fact
DEKABANK DEUTSCHE GIROZENTRALE)
SIGNED by ) /s/ Enrico Semprebene
duly authorised ) Enrico Semprebene
for and on behalf of)
CASSA DEPOSITI E PRESTITI S.P.A.)
SIGNED by ) /s/ Luca Geronimi
duly authorised ) Luca Geronimi
for and on behalf of) Attorney
BANCO BPM S.P.A.)
) /s/ Roberta Zanaboni
) Roberta Zanaboni
) Attorney
)
MANDATED LEAD ARRANGERS
SIGNED by ) /s/ Cosmo Fisher
duly authorised) Cosmo Fisher
for and on behalf of) Attorney-in-Fact
CRÉDIT AGRICOLE CORPORATE)
Leonardo Two
Amendment and Restatement Agreement
AND INVESTMENT BANK )/s/ Bruno Cloquet
SIGNED by ) Bruno Cloquet
duly authorised ) Global Head of Exporters and ECAs Origination
for and on behalf of)
BNP PARIBAS FORTIS S.A./N.V ) /s/ Michel Froidebise
) Michel Froidebise
)Head of Export Finance Nordic Origination
SIGNED by ) /s/ Varsha Sharan
duly authorised ) Varsha Sharan
for and on behalf of) Director
HSBC BANK PLC)
SIGNED by ) /s/ Enrico Semprebene
duly authorised ) Enrico Semprebene
for and on behalf of)
CASSA DEPOSITI E PRESTITI S.P.A.)
AGENT
SIGNED by ) /s/ Cosmo Fisher
duly authorised ) Cosmo Fisher
for and on behalf of) Attorney-in-Fact
CRÉDIT AGRICOLE CORPORATE AND)
INVESTMENT BANK )
SACE AGENT
SIGNED by ) /s/ Cosmo Fisher
duly authorised ) Cosmo Fisher
for and on behalf of) Attorney-in-Fact
CRÉDIT AGRICOLE CORPORATE AND)
INVESTMENT BANK )
SECURITY TRUSTEE
SIGNED by ) /s/ Cosmo Fisher
duly authorised ) Cosmo Fisher
for and on behalf of) Attorney-in-Fact
CRÉDIT AGRICOLE CORPORATE AND)
INVESTMENT BANK )
Form of Amended and Restated Facility Agreement (marked to indicate amendments)
Amendments are indicated as follows:
1 | additions are indicated by underlined text in blue; and |
2 | deletions are shown by strike-through text in red. |
Originally dated 12 April 2017
(as amended and restated by an amendment and restatement agreement dated 21 November 2017, as amended by a supplemental agreement dated 4 June 2020, as amended and restated by an amendment and restatement agreement dated 17 February 2021 and as further amended and restated pursuant toby an amendment and restatement agreement dated _____ February_______________ 2021)
Term Loan Facility
LEONARDO two, LTD.
as Borrower
and
The Banks and Financial Institutions
listed in Schedule 1
as Lenders
and
Crédit Agricole Corporate and Investment Bank
BNP PARIBAS Fortis S.A./N.V.
HSBC Bank PLC
CASSA DEPOSITI E PRESTITI S.P.A.
as Joint Mandated Lead Arrangers
and
Crédit Agricole Corporate and Investment Bank
as Agent and SACE Agent
and
Crédit Agricole Corporate and Investment Bank
as Security Trustee
with the support of
SACE S.p.A.
AMENDED AND RESTATED Facility Agreement
relating to the part financing of the 3,300 passenger cruise ship
newbuilding presently designated as
Hull No. [*] at Fincantieri S.p.A.
Index
Schedules
Execution
THIS AGREEMENT is originally made on 12 April 2017 (as amended and restated by an amendment and restatement agreement dated 21 November 2017, as amended by a supplemental agreement dated 4 June 2020, as amended and restated by an amendment and restatement dated 17 February 2021 and as further amended and restated pursuant toby an amendment and restatement agreement dated _____ February_______________ 2021)
(1) | LEONARDO TWO, LTD., an exempted company incorporated under the laws of Bermuda whose registered office is at Park Place 55, Par-la-Ville Road, Hamilton HM 11, Bermuda as borrower (the "Borrower") |
(2) | THE BANKS AND FINANCIAL INSTITUTIONS listed in Schedule 1 (Lenders and Commitments) as lenders (the "Lenders") |
(5) | CRÉDIT AGRICOLE CORPORATE AND INVESTMENT BANK, acting though its office at 12 Place des États-Unis, CS 70052, 92547, Montrouge Cedex, France, as security trustee (the "Security Trustee") |
(B) | The total price payable by the Borrower to the Builder under the Shipbuilding Contract is eight hundred million Euros (€800,000,000) (the "Initial Contract Price") payable on the following terms: |
(ii) | as to [*], being [*], on the later of the date of commencement of steel cutting and the date falling 24 months prior to the Intended Delivery Date; |
(iii) | as to [*], being [*], on the later of keel laying in dry-dock and the date falling 18 months prior to the Intended Delivery Date; |
(iv) | as to [*], being [*], on the later of launching and the date falling 12 months prior to the Intended Delivery Date; and |
(v) | as to [*], being [*], on delivery of the Ship on the Delivery Date, |
as each such event is described in the Shipbuilding Contract.
(E) |
(ii) | the next instalment under the Shipbuilding Contract is covered by a Refund Guarantee. |
(H) | Due to the unprecedented and extraordinary impacts of the Covid-19 pandemic on the cruise sector and cruise operators, SACE informed the cruise operators of its availability to evaluate |
certain measures (the "Temporary Measures") applicable in relation to certain qualifying loan agreements in order to assist companies which are financially sound but dealing with the impact of the temporary but unprecedented Covid-19 pandemic; the possibility to access to such measures was subject, amongst other things, to certain principles titled "Cruise Debt Holiday Principles" offered by SACE dated 15 April 2020 for cruise lines offered by SACE (the "Original Principles").
Agreement, as amended by the 2020 Amendment Agreement and as amended and restated by the February 2021 Amendment and Restatement Agreement, the "Facility Agreement").
This Agreement sets out the terms and conditions of the Facility Agreement as amended and restated by the June 2021 Amendment and Restatement Agreement. |
1 |
1.1 |
Subject to Clause 1.6 (General Interpretation), in this Agreement:
"2017 Amending and Restating Agreement" has the meaning given to such term in Recital G.
"2020 Amendment Agreement" has the meaning given to such term in Recital J.
"2020 Deferral Effective Date" has the meaning given to the term Effective Date in the 2020 Amendment Agreement.
"2020 Deferral Fee Letters" means any letter between the Agent and any Obligor which sets out the fees payable in connection with the arrangements contemplated by the 2020 Amendment Agreement.
"2021 Amendment and Restatement Agreement" has the meaning given to such term in Recital M.
"2021 Deferral Effective Date" has the meaning given to the term Effective Date in the February 2021 Amendment and Restatement Agreement.
"2021 Deferral Fee Letters" means any letter between the Agent or the SACE Agent and any Obligor which sets out the fees payable in connection with the arrangements contemplated by the February 2021 Amendment and Restatement Agreement.
"Acceptable Deposit" means a cash deposit for an amount equal to the cumulative total of the principal and interest secured by the relevant Refund Guarantee which is to be paid by the Builder (a) for security purposes in favour of the Borrower and under its control, the Builder
agreeing that it shall not have any control rights in respect of the deposit, that the Borrower may freely assign, charge, pledge or otherwise convey its rights in relation to the deposit to its financiers and SACE without the need to seek or obtain any approval or consent from the Builder, and that the Borrower shall be entitled to claim payment of the deposit in the same circumstances that it could claim payment of a Refund Guarantee, and (b) to the Account Bank by or before the relevant due date for payment of the deposit in accordance with Article 10.3 of the Shipbuilding Contract.
"Account" means a Euro account of the Borrower opened or to be opened with the Account Bank and subject to an Account Pledge.
"Account Bank" means Crédit Agricole Corporate and Investment Bank, being pursuant to the terms of the Shipbuilding Contract, the legal person designated by written notice by the Borrower to the Builder at any time to hold an Acceptable Deposit.
"Account Pledge" means any pledge of an Acceptable Deposit granted in favour of the Security Trustee, the Joint Mandated Lead Arrangers, the Agent, the SACE Agent and the Lenders.
"Additional SACE Premium" has the meaning given to such term in Clause 8.5 (Additional Premium).
"Advance" means the principal amount of each borrowing of all or part of a Tranche by the Borrower under this Agreement.
"Affiliate" means in relation to any person, a Subsidiary of that person or a Holding Company of that person or any other Subsidiary of that Holding Company.
"Agent" means Crédit Agricole Corporate and Investment Bank, a French "société anonyme", having a share capital of seven billion eight hundred and fifty one million six hundred and thirty six thousand three hundred and forty two Euros (€7,851,636,342.00) and its registered office located at 12, Place des États-Unis, CS 70052, 92547 Montrouge Cedex, France, registered under the n° Siren 304 187 701 at the Registre du Commerce et des Sociétés of Nanterre or any successor of it appointed under Clause 26 (Role of the Agent and the Joint Mandated Lead Arrangers).
"Aggregate SACE Premium" means, together, the SACE Premium, the Additional SACE Premium and the Tranche B Premium.
"Amended Maximum Loan Amount" means the aggregate of:
the Original Maximum Loan Amount, financed or to be financed pursuant to Tranche A, provided that such amount shall not, at any time, exceed the Total Tranche A Commitments; |
the Dollar Equivalent of Euros one hundred eighty-five million six hundred thousand (€185,600.000), corresponding to the amount to be financed in relation to the Upsize Allowance, financed or to be financed pursuant to Tranche B; |
100% of the Tranche B Premium to be paid in accordance with paragraph (a) of Clause 8.6 (Tranche B Premium), |
provided that such amount shall not, at any time, exceed the Total Tranche B Commitments; and
provided that such aggregate amount shall not, at any time, exceed the Total Commitments.
"Annex VI" means Annex VI (Regulations for the Prevention of Air Pollution from Ships, entered into on 19 May, 2005) to the International Convention for the Prevention of Pollution from Ships 1973, as modified by the Protocol of 1978 relating thereto and by the Protocol of 1997 (MARPOL) and as further revised in October 2008 with such revised version having entered into force on 1 July 2010.
"Approved Broker" means Clarkson Platou, Barry Rogliano Salles, Fearnleys AS, Rocca & Partners, Brax Shipbrokers AS (or any Affiliate of such person through which valuations are commonly issued) or such other shipbroker or ship valuer experienced in valuing cruise ships nominated by the Borrower and approved by the Agent.
"Approved Flag" means the Bermudian flag, the Marshall Islands flag, the Bahamas flag or such other flag as the Agent may, with the approval of the Italian Authorities and at least three Lenders representing as a minimum the Majority Lenders, approve from time to time.
"Approved Manager" means any of the Borrower, NCL Corporation Ltd., NCL (Bahamas) Ltd. or other member of the Group, or any company which is not a member of the Group which the Agent may, with the authorisation of the Majority Lenders, approve from time to time as the manager of the Ship.
"Approved Manager's Undertaking" means, in the event that the Approved Manager is a company other than the Borrower, a letter of undertaking executed or to be executed by the Approved Manager in favour of the Agent, which will include, without limitation, an agreement by the Approved Manager to subordinate its rights against the Ship and the Borrower to the rights of the Secured Parties under the Finance Documents, in the agreed form.
"Article 55 BRRD" means Article 55 of Directive 2014/59/EU establishing a framework for the recovery and resolution of credit institutions and investment firms.
"Availability Period" means, in relation to Tranche A, the period commencing on the date of the Original Facility Agreement and, in relation to Tranche B and Tranche C, the period commencing on the date of this Agreement, and ending on:
(a) | the earlier to occur of (i) the Delivery Date and (ii) 25 February26 January 2024 (or such later date as the Agent may, with the authorisation of the Lenders, agree with the Borrower); or |
(b) | if earlier, the date on which the Total Commitments are fully borrowed, cancelled or terminated. |
"Bail-In Action" means the exercise of any Write-down and Conversion Powers.
"Base Rate" means one Euro for [*] Dollars.
"Bermudian Obligors" means the Borrower, the Shareholder and the Guarantor.
"Builder" has the meaning given in Recital (A).
(a) | for the purposes of Recital (B) above, a day (other than a Saturday or a Sunday) on which banks are open in Paris, New York, Milan and Rome; and |
"CDP" means Cassa Depositi e Prestiti S.p.A..
"Certified Copy" means in relation to any document delivered or issued by or on behalf of any company, a copy of such document certified as a true, complete and up-to-date copy of the original by any of the directors or the secretary or assistant secretary or any attorney-in-fact for the time being of that company.
"Charged Property" means all of the assets which from time to time are, or are expressed to be, the subject of Security Interests pursuant to the Finance Documents.
"CIRR" (Commercial Interest Reference Rate) means two point fifty-three per cent. (2.53%) per annum or any other CIRR rate being the fixed rate for medium and long term export credits in Dollars applicable to the financing of the Ship according to the Organisation for Economic Co-operation and Development rules as determined by the competent Italian Authorities.
"Code" means the United States Internal Revenue Code of 1986.
"Code of Ethics" means the code of ethics adopted by CDP, available on CDP's website (http://www.cdp.it/static/upload/cdp/cdp_code_ethics.pdf).
"Commitment" means, in relation to a Lender, the percentage of the Maximum Loan Amount set opposite its name in Schedule 1 (Lenders and Commitments), or, as the case may require, the amount specified in the relevant Transfer Certificate, as that amount may be reduced, cancelled or terminated in accordance with this Agreement (and "Total Commitments" means
the aggregate of the Commitments of all the Lenders).a Tranche A Commitment, a Tranche B Commitment or a Tranche C Commitment.
"Compliance Certificate" has the meaning given to the term "Compliance Certificate" in the Guarantee.
"Confidential Information" means all information relating to any Obligor, the Group, the Finance Documents or the Loan of which a Secured Party becomes aware in its capacity as, or for the purpose of becoming, a Secured Party or which is received by a Secured Party in relation to, or for the purpose of becoming a Secured Party under, the Finance Documents or the Loan from either:
(a) |
(b) | another Secured Party, if the information was obtained by that Secured Party directly or indirectly from any member of the Group or any of its advisers, |
in whatever form, and includes information given orally and any document, electronic file or any other way of representing or recording information which contains or is derived or copied from such information but excludes information that:
(i) | is or becomes public information other than as a direct or indirect result of any breach by that Secured Party of Clause 33 (Confidentiality); or |
(ii) | is identified in writing at the time of delivery as non-confidential by any member of the Group or any of its advisers; or |
"Confidentiality Undertaking" means a confidentiality undertaking in substantially the appropriate form recommended by the LMA from time to time or in any other form agreed between the Borrower and the Agent.
"Contribution" means, in relation to a Lender, the part of the Loan which is owing to that Lender.
"Conversion Rate" means the rate determined by the Agent on the Conversion Rate Fixing Date and notified to the Borrower as being the lower of:
(a) |
(b) |
"Conversion Rate Fixing Date" means:
(a) | in respect of each Advance under a Tranche save for the Delivery Advance under that Tranche, the date falling [*] days before the relevant Drawdown Date under that Tranche; and |
(b) | in respect of the Delivery Advance under a Tranche, the date falling [*] days before the Delivery Date. |
"Corresponding Debt" means any amount, other than any Parallel Debt, which an Obligor owes to a Creditor Party under or in connection with the Finance Documents.
"Creditor Party" means the Agent, the Security Trustee, the SACE Agent, the Joint Mandated Lead Arrangers or any Lender, whether as at the date of the Original Facility Agreement or at any later time.
"Deferral Fee Letters" means any of the 2020 Deferral Fee Letters and/or the 2021 Deferral Fee Letters.
"Deferral Period" means the period from 1 April 2020 to 31 December 2022.
"Delivery Advance" means, subject to the provisions of Clause 8.4 (Refund) and paragraphs (e) and (f) of Clause 8.6 (Tranche B Premium), the Advance under a Tranche to be made available (as applicable) for drawing on the Delivery Date.
"Delivery Date" means the date and time of delivery of the Ship by the Builder to the Borrower as stated in the Protocol of Delivery and Acceptance.
"Document of Compliance" has the meaning given to it in the ISM Code.
"Dollar Equivalent" means such amount in Dollars as is calculated by the Agent on the Conversion Rate Fixing Date to be the equivalent of an amount in Euro at the Conversion Rate.
"Dollars" and "$" means the lawful currency for the time being of the United States of America.
"Downgraded Refund Guarantor" means a Refund Guarantor who has become subject to a RG Downgrade Event.
"Drawdown Date" means, in relation to an Advance under a Tranche, the date on which that Advance is drawn down and applied in accordance with Clause 2 (Facility).
"Drawdown Notice" means a notice in the form set out in Schedule 2 (Form of Drawdown Notice) (or in any other form which the Agent approves or reasonably requires).
"Earnings" means all moneys whatsoever which are now, or later become, payable (actually or contingently) to the Borrower and which arise out of the use or operation of the Ship, including (but not limited to):
(b) | all moneys which are at any time payable under Insurances in respect of loss of earnings; |
(c) | all moneys which are at any time payable to the Borrower in respect of the general average contribution; and |
"EEA Member Country" means any member state of the European Union, Iceland, Liechtenstein and Norway.
"Eligible Amount" means eighty per cent. (80%) of the lesser of:
(a) | the Dollar Equivalent of eight hundred million Euros (€800,000,000); and |
(b) |
"Environmental Approval" means any present or future permit, ruling, variance or other authorisation required under Environmental Laws.
"Environmental Claim" means any claim by any governmental, judicial or regulatory authority or any other person which arises out of an Environmental Incident or an alleged Environmental Incident or which relates to any Environmental Law and, for this purpose, "claim" includes a claim for damages, compensation, contribution, injury, fines, losses and penalties or any other payment of any kind, including in relation to clean-up and removal, whether or not similar to the foregoing; an order or direction to take, or not to take, certain action or to desist from or suspend certain action; and any form of enforcement or regulatory action, including the arrest or attachment of any asset.
"Environmental Incident" means:
"Environmental Law" means any present or future law relating to pollution or protection of human health or the environment, to conditions in the workplace, to the carriage, generation, handling, storage, use, release or spillage of Environmentally Sensitive Material or to actual or threatened releases of Environmentally Sensitive Material.
"Environmentally Sensitive Material" means and includes all contaminants, oil, oil products, toxic substances and any other substance (including any chemical, gas or other hazardous or noxious substance) which is (or is capable of being or becoming) polluting, toxic or hazardous.
"Equator Principles" means the standards entitled "A financial industry benchmark for determining, assessing and managing environmental and social risk in projects" dated June 2013 and adopted by certain financial institutions, as the same may be amended or supplemented from time to time.
"EU Bail-In Legislation Schedule" means the document described as such and published by the Loan Market Association (or any successor person) from time to time.
"Euro" and "EUR" means the single currency of the Participating Member States.
"Event of Default" means any of the events or circumstances described in Clause 18.1 (Events of Default).
"Existing Indebtedness" means Financial Indebtedness referred to in the financial statements of the Guarantor delivered to the Agent prior to the date of this Agreement.
"Exporter Declaration" means a declaration to be issued for Advances under Tranche A and Tranche B in respect of which interest is payable at the Fixed Interest Rate, in the form required by SIMEST at the relevant time duly signed by an authorised signatory of the Builder.
"Facility" means the term loan facility under Tranche A, Tranche B and Tranche C, made or to be made available under this Agreement as described in Clause 2.1 (Amount of facility).
"Facility Agreement" has the meaning given to such term in Recital (JM).
"Facility Office" means the office or offices notified by a Lender to the Agent in writing on or before the date it becomes a Lender (or, following that date, by not less than five (5) Business Days' written notice) as the office or offices through which it will perform its obligations under this Agreement.
(a) | sections 1471 to 1474 of the Code or any associated regulations; |
"FATCA Application Date" means:
(a) | in relation to a "withholdable payment" described in section 1473(1)(A)(i) of the Code (which relates to payments of interest and certain other payments from sources within the US), 1 July 2014; |
(c) | in relation to a "passthru payment" described in section 1471(d)(7) of the Code not falling within paragraphs (a) or (b) above, 1 January 2019, |
or, in each case, such other date from which such payment may become subject to a deduction or withholding required by FATCA as a result of any change in FATCA after the date of the Original Facility Agreement.
"FATCA Deduction" means a deduction or withholding from a payment under a Finance Document required by FATCA.
"FATCA Exempt Party" means a Party that is entitled to receive payments free from any FATCA Deduction.
"February 2021 Amendment and Restatement Agreement" has the meaning given to such term in Recital (M).
"Fee Letter" means any letter dated on or about the date of the Original Facility Agreement between the SACE Agent and the Borrower setting out the fees referred to in paragraph (d) of Clause 9 (Fees).
(a) |
(b) |
(c) |
(d) | the Deferral Fee LettersJune 2021 Amendment and Restatement Agreement; |
(e) | this Agreement; |
(f) |
any other document (whether creating a Security Interest or not) which is designated as a Finance Document by agreement between the Borrower, SACE and the Agent. |
"Final Contract Price" has the meaning given in Recital (C).
"Financial Indebtedness" means, in relation to a person (the "debtor"), a liability of the debtor:
(a) | for principal, interest or any other sum payable in respect of any moneys borrowed or raised by the debtor; |
(b) | under any loan stock, bond, note or other security issued by the debtor; |
(c) | under any acceptance credit, guarantee or letter of credit facility made available to the debtor; |
(d) | under a financial lease, a deferred purchase consideration arrangement or any other agreement having the commercial effect of a borrowing or raising of money by the debtor; |
(g) | arising from receivables sold or discounted (other than receivables to the extent they are sold on a non-recourse basis). |
"First Instalment" means the first instalment of the SACE Premium as more particularly described in paragraph (a) of Clause 8.1 (SACE Premium).
"Fixed Interest Rate" means, in respect of any Interest Period, the rate per annum determined by the Agent to be the aggregate of:
(a) |
(b) |
"Floating Interest Rate" means, in respect of any Interest Period, the rate per annum determined by the Agent to be the aggregate of:
(a) |
(b) |
"FOREX Contracts" means each actual purchase contract, spot or forward contract and any other contract, such as an option or collar arrangement, which is entered into in the foreign exchange markets for the acquisition of Euro intended to pay the instalments under the Shipbuilding Contract, which:
"FOREX Contracts Weighted Average Rate" means the rate determined by the Agent on the Conversion Rate Fixing Date in accordance with the following principles which (inter alia) are intended to take into account any maturity mismatch between the maturity of the FOREX Contracts and each Drawdown Date as well as FOREX Contracts that are unwound as part of the hedging strategy of the Borrower:
(a) | FOREX Contracts that are spot or forward foreign exchange contracts, if any, shall be valued at the contract value (taking into account any rescheduling); |
Any marked to market valuation, as required in paragraph (c) above, shall be performed by Crédit Agricole Corporate and Investment Bank's dedicated desk in accordance with market practices. The Borrower shall have the right to request indicative valuations from time to time prior to the Conversion Rate Fixing Date.
"Funding Rate" means any individual rate notified by a Lender to the Agent pursuant to sub-paragraph (ii) of paragraph (a) of Clause 6.9 (Cost of funds).
"GAAP" means generally accepted accounting principles in the United States of America consistently applied (or, if not consistently applied, accompanied by details of the inconsistencies) including, without limitation, those set forth in the opinion and pronouncements of the Accounting Principles Board of the American Institute of Certified Public Accountants and statements and pronouncements of the Financial Accounting Standards Board.
"General Assignment" means an assignment of any Management Agreement, the Earnings, the Insurances and any Requisition Compensation, executed or to be executed by the Borrower and, in the event that the Approved Manager is not a member of the Group and is named as a co-assured in the Insurances, the Approved Manager in favour of the Security Trustee in the agreed form.
"Gross Negligence" means any act or omission, whether deliberate or not, which in the circumstances (including both the probability and seriousness of the consequences likely to result) would reasonably be regarded by those familiar with the nature of the activity in question and with the surrounding circumstances, as amounting to the reckless disregard of, or serious indifference to, the consequences, being in any case more than a negligent failure to exercise proper skill and care.
"Group" means the Guarantor and its Subsidiaries.
"Guarantee" means the Original Guarantee, as amended pursuant to the 2020 Amendment Agreement and as amended and restated pursuant to the February 2021 Amendment and Restatement Agreement, and as may be further amended and/or supplemented from time to time.
"Guarantor" means NCL Corporation Ltd., a Bermuda company with its registered office at Park Place 55, Par-la-Ville Road, Hamilton HM 11, Bermuda.
"Holding" means Norwegian Cruise Line Holdings Ltd., a company incorporated under the laws of Bermuda with its registered office at Park Place 55, Par-la-Ville Road, Hamilton HM 11, Bermuda.
"Holding Company" means, in relation to a person, any other person in respect of which it is a Subsidiary.
"IAPPC" means a valid international air pollution prevention certificate for the Ship issued under Annex VI.
"Illicit Origin" means any origin which is illicit, fraudulent or in breach of Sanctions including, without limitation, drug trafficking, corruption, organised criminal activities, terrorism, money laundering or fraud.
"Initial Contract Price" has the meaning given in Recital (B).
(b) | all rights and other assets relating to, or derived from any of such policies, contracts or entries, including any rights to a return of a premium. |
"Intended Delivery Date" means [*] (the date on which the Ship will be ready for delivery pursuant to the Shipbuilding Contract as at the date of the Original Facility Agreement) or any other date notified by the Borrower to the Agent in accordance with paragraph (a) of Clause 3.123.13 (No later than sixty (60) days before the Intended Delivery Date) or paragraph (b) of Clause 3.143.15 (No later than five (5) Business Days before the Intended Delivery Date) as being the date on which the Builder and the Borrower have agreed that the Ship will be ready for delivery pursuant to the Shipbuilding Contract.
"Interest Make-Up Agreement" means an interest make up agreement (Capitolato) to be entered into between SIMEST and the Agent on behalf of the Lenders and in form and substance acceptable to the Joint Mandated Lead Arrangers, whereby, inter alia, the return to the Lenders on the Loan made hereunder will be supplemented by SIMEST so that it equals that which the Lenders would have received if interest were payable on the Loan at LIBOR plus the Margin.
"Interest Period" means a period determined in accordance with Clause 7 (Interest Periods).
"Interpolated Screen Rate" means, in relation to the Loan or any part of the Loan, the rate which results from interpolating on a linear basis between:
(a) | the applicable Screen Rate for the longest period (for which that Screen Rate is available) which is less than the Interest Period of the Loan or that part of the Loan; and |
(b) | the applicable Screen Rate for the shortest period (for which that Screen Rate is available) which exceeds the Interest Period of the Loan or that part of the Loan, |
each as of the Specified Time for Dollars.
"ISM Code" means the International Safety Management Code for the safe operation of ships and for pollution prevention (including the guidelines on its implementation), adopted by the International Maritime Organisation as the same may be amended or supplemented from time to time.
"ISPS Code" means the International Ship and Port Facility Security (ISPS) Code adopted by the International Maritime Organisation (IMO) Diplomatic Conference of December 2002, as the same may be amended or supplemented from time to time.
"Italian Authorities" means SACE and/or SIMEST and any other relevant Italian authorities involved in the implementation of the Loan.
"June 2021 Amendment and Restatement Agreement" has the meaning given to this term in Recital (O).
"June 2021 Fee Letters" means any letter between the Agent or the SACE Agent and any Obligor which sets out the fees payable in connection with the arrangements contemplated by the June 2021 Amendment and Restatement Agreement.
"Legislative Decree 231/01" means the Italian legislative decree of 8 June 2001, no. 231 (Disciplina della responsabilità amministrativa delle persone giurdiche, delle società e delle associazioni anche prive di personalità giuridica, a norma dell'articolo 11 della legge 29 settembre 2000, n.300) as amended from time to time, on administrative vicarious liability of corporate entities.
"Lender" means a bank, financial institution, trust, fund or other entity listed in Schedule 1 (Lenders and Commitments) and acting through its Facility Office or its transferee, successor or assign.Tranche A Lender, a Tranche B Lender or a Tranche C Lender.
"LIBOR" means, in relation to the Loan or any part of the Loan:
(a) | the applicable Screen Rate as of the Specified Time for Dollars and for a period equal in length to the Interest Period of the Loan or that part of the Loan; or |
(b) | as otherwise determined pursuant to Clause 6.6 (Unavailability of Screen Rate). |
and if, in either case, that rate is less than zero, LIBOR shall be deemed to be zero.
"Loan" means the aggregate principal amount outstanding for the time being outstanding under this Agreementof the borrowings under the Facility and a "part of the Loan" means an Advance, a Tranche or a part of a Tranche.
(a) | before the first Advance under Tranche A has been made, Lenders whose Commitments total [*] per cent. of the Total Commitments; and |
(b) | after any Advance under any Tranche has been made, Lenders whose Contributions total [*] per cent. of the Loan. |
"Management Agreement" means the management agreement (if any) entered or to be entered into between the Borrower and an Approved Manager which is not a member of the Group with respect to the Ship on terms reasonably acceptable to the Majority Lenders and SACE.
(a) | in relation to the Fixed Interest Rate zero point twenty-four per cent. (0.24%) per annum; and |
(b) | in relation to the Floating Interest Rate one point seventy-four per cent. (1.74%) per annum. |
"Maritime Registry" means the maritime registry which the Borrower will specify to the Lenders no later than 90 days before the Intended Delivery Date, being that of Bermuda, the Marshall Islands, Bahamas or such other registry as the Agent may, with the approval of the Italian Authorities and at least three Lenders representing as a minimum the Majority Lenders, approve.
"Material Adverse Effect" means the occurrence of any event or circumstance which reasonably would be expected to have a material adverse effect on:
(a) | the business, operations, property, condition (financial or otherwise) of any Obligor or the Group as a whole; or |
(b) | the ability of any Obligor to perform its obligations under any Finance Document and/or any Pre-delivery Contract; or |
"Material Provisions" means Article 1 (Subject of the Contract), Article 2 (Vessel's Classification – Rules and Regulations – Certificates), Article 8 (Delivery), Article 9 (Price), Article 13 (Speed – Liquidated Damages), Article 14 (Deadweight – Liquidated Damages), Article 17 (Fuel Oil Consumption – Liquidated Damages), Article 19 (Maximum Amount of Liquidated Damages), Article 20 (Termination of the Contract – Liquidated Damages to be paid by the Builder), Article 23 (Insurance), Article 25 (Guarantee – Liability), Article 26 (Permissible Delay), Article 29 (Assignment of the Contract), and Article 30 (Law of the Contract – Disputes) of the Shipbuilding Contract.
"Maximum Loan Amount" means the aggregate of:
the Dollar Equivalent of six hundred and forty million Euros (€640,000,000.00); and |
one hundred per cent. (100%) of the SACE Premium to be paid in accordance with Clause 8.1 (SACE Premium), |
provided that such amount shall not, at any time, exceed eight hundred and sixty-eight million, one hundred and eight thousand, one hundred and eight Dollars and eleven Cents ($868,108,108.11).
"Minor Modification" means a modification of the plans or the specification or the construction of the Ship under Article 24 of the Shipbuilding Contract, resulting in a contract price increase or decrease of less than [*] Euros (€[*]).
"Model" means the principles of the compliance system adopted by CDP pursuant to Legislative Decree 231/01, available on CDP's website (http://www.cdp.it/static/upload/pri/ principles-of-the-compliance-system.pdf).
"Mortgage" means the first priority mortgage on the Ship acceptable for registration on the Approved Flag and, if applicable, deed of covenant, executed or to be executed by the Borrower in favour of the Security Trustee in the agreed form.
"Obligors" means the Borrower, the Guarantor, the Shareholder and (in the event that the Approved Manager is a member of the Group) the Approved Manager.
"Original Facility Agreement" has the meaning given to such term in Recital (D).
"Original Guarantee" means the guarantee issued by the Guarantor in favour of the Security Trustee on 12 April 2017.
"Original Jurisdiction" means, in relation to an Obligor, the jurisdiction under whose laws that Obligor is incorporated as at the date of this Agreement.
"Original Maximum Loan Amount" means the aggregate of:
the Dollar Equivalent of six hundred and forty million Euros (€640,000,000.00); and |
one hundred per cent. (100%) of the SACE Premium to be paid in accordance with Clause 8.1 (SACE Premium), |
provided that such amount shall not, at any time, exceed eight hundred and sixty-eight million, one hundred and eight thousand, one hundred and eight Dollars and eleven Cents ($868,108,108.11).
"Original Principles" has the meaning given in Recital (H)
"Overnight LIBOR" means, in relation to the Loan or any part of the Loan:
(a) | on any date, the applicable day to day Screen Rate as of the Specified Time for Dollars; or |
(b) | as otherwise determined pursuant to Clause 6.6 (Unavailability of Screen Rate), |
and if, in either case, that rate is less than zero, Overnight LIBOR shall be deemed to be zero.
"Overseas Regulations" means the United Kingdom Overseas Companies Regulations 2009.
"Parallel Debt" means any amount which an Obligor owes to the Security Trustee under Clause 27.2 (Parallel Debt (Covenant to pay the Security Trustee)).
"Participating Member State" means any member state of the European Union that adopts or has adopted the euro as its lawful currency in accordance with legislation of the European Union relating to Economic and Monetary Union.
"Party" means a party to this Agreement from time to time.
"Permitted Financial Indebtedness" means any Financial Indebtedness:
(a) |
(b) | permitted pursuant to Clause 12.14 (Financial Indebtedness and subordination of indebtedness). |
"Permitted Security Interests" means:
(a) |
(i) | any of the Security Interests referred to in paragraph (b)(ii)(A) below; and |
(b) |
(i) | any of the Security Interests referred to in paragraphs (b)(ii)(A), (b)(ii)(D), (b)(ii)(F) and (b)(ii)(G) below; and |
(B) | liens on the Ship up to an aggregate amount at any time not exceeding [*] for current crew's wages and salvage and liens incurred in the ordinary course of trading the Ship; |
(C) | any deposits or pledges up to an aggregate amount at any time not exceeding [*] to secure the performance of bids, tenders, bonds or contracts required in the ordinary course of business; |
(H) | liens in favour of credit card companies on unearned customer deposits pursuant to agreements therewith; and |
(I) |
(a) |
(b) | any policy or contract of insurance contemplated by or referred to in Clause 12 (General Undertakings) or any other provision of this Agreement or another Finance Document; |
(c) | any other document contemplated by or referred to in any Finance Document; and |
(a) | any transaction or matter contemplated by, arising out of, or in connection with a Pertinent Document; or |
(b) | any statement relating to a Pertinent Document or to a transaction or matter falling within paragraph (a); |
and covers any such transaction, matter or statement, whether entered into, arising or made at any time before the signing of this Agreement or on or at any time after that signing.
"Poseidon Principles" means the financial industry framework for assessing and disclosing the climate alignment of ship finance portfolios published in June 2019 as the same may be amended or replaced to reflect changes in applicable law or regulation or the introduction of or changes to mandatory requirements of the International Maritime Organisation from time to time.
"Post-Delivery Assignment" means an assignment of the rights of the Borrower in respect of the post-delivery guarantee liability of the Builder under Article 25 of the Shipbuilding Contract executed or to be executed by the Borrower in favour of the Security Trustee in the agreed form.
"Pre-delivery Contracts" means the Shipbuilding Contract and the Refund Guarantee.
"Pre-delivery Security" means:
(a) | any document creating security over the Pre-delivery Contracts in agreed form; and/or |
(b) |
"Principles" has the meaning given in Recital (K).
"Prohibited Person" means any person (whether designated by name or by reason of being included in a class of persons) against whom Sanctions are directed.
"Protocol of Delivery and Acceptance" means the protocol of delivery and acceptance of the Ship to be signed by the Borrower and the Builder in accordance with Article 8 of the Shipbuilding Contract.
"Qualifying Certificate" means the certificate to be issued by the Builder on each Drawdown Date under Tranche A and under Tranche B and issued to the Agent and copied to the Borrower substantially in the form set out in Schedule 5 (Qualifying Certificate).
"Quotation Day" means in relation to any period for which an interest rate is to be determined, two Business Days before the first day of that period unless market practice differs in the Relevant Interbank Market in which case the Quotation Day will be determined by the Agent in accordance with market practice in the Relevant Interbank Market (and if quotations would normally be given by leading banks in the Relevant Interbank Market on more than one day, the Quotation Day will be the last of those days).
"Reference Bank Quotation" means any quotation supplied to the Agent by a Reference Bank.
"Reference Bank Rate" means the arithmetic mean of the rates (rounded upwards to four decimal places) as supplied to the Agent at its request by the Reference Banks:
as the rate (applied to the relevant Reference Bank and the relevant currency and period) which contributors to the Screen Rate are asked to submit to the relevant administrator; or
in any other case, as the rate at which the relevant Reference Bank could fund itself in Dollars for the relevant period with reference to the unsecured wholesale funding market. |
"Reference Banks" means such entities as may be appointed by the Agent in consultation with the Borrower.
"Refund Guarantee" means any irrevocable and unconditional guarantee issued or to be issued by a Refund Guarantor in favour of the Borrower under the Shipbuilding Contract in the form annexed to the Sixth Addendum or in any other form acceptable to the Joint Mandated Lead Arrangers and the SACE Agent.
"Refund Guarantor" means a bank, insurance company or other financial institution acceptable to the Lenders and SACE which, at the time of issue by it of a Refund Guarantee, has a minimum credit rating of at least BBB- at Standard & Poor's (or, where the relevant Refund Guarantor is not rated by Standard & Poor's, the equivalent rating at Moody's or where the relevant Refund Guarantor is not rated by Standard & Poor's or Moody's, the equivalent rating at Fitch).
"Relevant Interbank Market" means the London interbank market.
"Relevant Jurisdiction" means, in relation to an Obligor:
(a) |
(c) |
(d) | the jurisdiction whose laws govern the perfection of any of the Security Interests created, or intended to be created, under the Finance Documents to which it is a party. |
"Relevant Nominating Body" means any applicable central bank, regulator or other supervisory authority or a group of them, or any working group or committee sponsored or chaired by, or constituted at the request of, any of them or the Financial Stability Board.
"Repayment Date" means a date on which a repayment is required to be made under Clause 5 (Repayment).
"Replacement Benchmark" means a benchmark rate which is:
formally designated, nominated or recommended as the replacement for a Screen Rate by: |
the administrator of that Screen Rate (provided that the market or economic reality that such benchmark rate measures is the same as that measured by that Screen Rate); or |
and if replacements have, at the relevant time, been formally designated, nominated or recommended under both paragraphs, the "Replacement Benchmark" will be the replacement under paragraph (Bii) above;
in the opinion of the Majority Lenders and the Borrower, generally accepted in the international or any relevant domestic syndicated loan markets as the appropriate successor to a Screen Rate; or |
in the opinion of the Majority Lenders and the Borrower, an appropriate successor to a Screen Rate. |
"Representative" means any delegate, agent, manager, administrator, nominee, attorney, trustee or custodian.
"Requisition Compensation" includes all compensation or other moneys payable by reason of any act or event such as is referred to in paragraph (b) of the definition of "Total Loss".
"Restricted Country" means a country or territory that is the subject of any comprehensive Sanctions barring dealings with such country or territory.
"Resolution Authority" means any body which has authority to exercise any Write-down and Conversion Powers.
"RG Downgrade Event" means an event which occurs when a Refund Guarantor ceases to maintain a credit rating of at least BBB- at Standard & Poor's (or, where the relevant Refund Guarantor is not rated by Standard & Poor's, the equivalent rating at Moody's or where the
relevant Refund Guarantor is not rated by Standard & Poor's or Moody's, the equivalent rating at Fitch).
"SACE" means SACE S.p.A., an Italian joint stock company (società per azioni) with a sole shareholder, whose registered office is located at Piazza Poli 37/42, 00187 Rome, Italy and registered with the Companies Registry of Rome under number 05804521002.
"SACE Agent" means Crédit Agricole Corporate and Investment Bank, a French "société anonyme", having a share capital of seven billion eight hundred and fifty one million six hundred and thirty six thousand three hundred and forty two Euros (€7,851,636,342.00) and its registered office located at 12, Place des États-Unis, CS 70052, 92547 Montrouge Cedex, France, registered under the n° Siren 304 187 701 at the Registre du Commerce et des Sociétés of Nanterre or any successor of it appointed under Clause 26 (Role of the Agent and the Joint Mandated Lead Arrangers).
"SACE Insurance Policy" means the insurance policy (as amended and supplemented from time to time) in respect of this Agreement (which, in all material respects, is not inconsistent with the commercial terms of this Agreement) issued or to be issued by SACE for the benefit of the Lenders in respect of one hundred per cent. (100%) of the Loan in form and substance satisfactory to the Agent and all the Lenders.
"SACE Premium" means the amount payable by the Borrower to SACE directly or through the Agent in two instalments, being the SACE Premium Instalments, in respect of the SACE Insurance Policy as set out in Clause 88.1 (SACE Premium and Italian Authorities), in addition to the Additional SACE Premium (provided, for the avoidance of doubt, that the Additional SACE Premium shall not be financed).
"SACE Premium Instalments" means each of the First Instalment and Second Instalment.
"SACE Required Documents" means in relation to each Drawdown Notice under Tranche A and under Tranche B:
(a) |
(b) | each of the other documents, information and other evidence specified in or required to be enclosed with such Qualifying Certificate. |
"Safety Management Certificate" has the meaning given to it in the ISM Code.
"Sanctions" means any sanctions, embargoes, freezing provisions, prohibitions or other restrictions relating to trading, doing business, investment, exporting, financing or making assets available (or other activities similar to or connected with any of the foregoing):
(b) | imposed by the U.S. Department of the Treasury's Office of Foreign Assets Control (OFAC); or |
(c) |
"Screen Rate" means the London interbank offered rate administered by ICE Benchmark Administration Limited (or any other person which takes over the administration of that rate) for Dollars for the relevant period displayed (before any correction, recalculation or republication by the administrator) on page LIBOR01 of the Thomson Reuters screen (or any replacement Thomson Reuters page which displays that rate) or on the appropriate page of such other information service which publishes that rate from time to time in place of Thomson Reuters. If such page or service ceases to be available, the Agent may specify another page or service displaying the relevant rate after consultation with the Borrower.
"Screen Rate Contingency Period" means fifteen (15) Business Days.
"Screen Rate Replacement Event" means, in relation to a Screen Rate:
(a) | the methodology, formula or other means of determining that Screen Rate has, in the opinion of the Majority Lenders and the Borrower materially changed; |
(A) | the administrator of that Screen Rate or its supervisor publicly announces that such administrator is insolvent; or |
provided that, in each case, at that time, there is no successor administrator to continue to provide that Screen Rate;
(iii) | the supervisor of the administrator of that Screen Rate publicly announces that such Screen Rate has been or will be permanently or indefinitely discontinued; or |
(iv) | the administrator of that Screen Rate or its supervisor announces that that Screen Rate may no longer be used; or |
in the case of a Screen Rate for LIBOR, the supervisor of the administrator of that Screen Rate makes a public announcement or publishes information: |
stating that that Screen Rate is no longer or, as of a specified future date will no longer be, representative of the underlying market or economic reality that it is intended to measure and that representativeness will not be restored (as determined by such supervisor); and |
with awareness that any such announcement or publication will engage certain triggers for fallback provisions in contracts which may be activated by any such pre-cessation announcement or publication; or |
(i) | the circumstance(s) or event(s) leading to such determination are not (in the opinion of the Majority Lenders and the Borrower) temporary; or |
(ii) | that Screen Rate is calculated in accordance with any such policy or arrangement for a period no less than the Screen Rate Contingency Period; or |
(d) | in the opinion of the Majority Lenders and the Borrower, that Screen Rate is otherwise no longer appropriate for the purposes of calculating interest under this Agreement. |
"Second Instalment" means the second instalment of the SACE Premium as more particularly described in paragraph (b) of Clause 8.1 (SACE Premium).
"Secured Liabilities" means all liabilities which the Borrower, the Obligors or any of them have, at the date of the Original Facility Agreement or at any later time or times, under or in connection with any Finance Document or any judgment relating to any Finance Document; and for this purpose, there shall be disregarded any total or partial discharge of these liabilities, or variation of their terms, which is effected by, or in connection with, any bankruptcy, liquidation, arrangement or other procedure under the insolvency laws of any country.
"Secured Party" means SACE, the Agent, the Security Trustee, the SACE Agent, the Joint Mandated Lead Arrangers or any Lender whether at the date of the Original Facility Agreement or any later time.
(b) | the security rights of a plaintiff under an action in rem; and |
"Security Period" means the period commencing on the date of the Original Facility Agreement and ending on the date on which:
(a) | all amounts which have become due for payment by the Borrower or any Obligor under the Finance Documents have been paid; |
(b) | no amount is owing or has accrued (without yet having become due for payment) under any Finance Document; |
(c) | the Security Trustee's interest in any turnover trust created under the Finance Documents; |
except:
(i) | rights intended for the sole benefit of the Security Trustee; and |
(ii) | any moneys or other assets which the Security Trustee has transferred to the Agent or (being entitled to do so) has retained in accordance with the provisions of this Agreement. |
"Security Requirement" means the amount in Dollars (as certified by the Agent whose certificate shall, in the absence of manifest error, be conclusive and binding on the Borrower and the Agent) which is at any relevant time one hundred and twenty-five per cent (125%) of the Loan.
"Security Trustee" means Crédit Agricole Corporate and Investment Bank, a French "société anonyme", having a share capital of seven billion eight hundred and fifty one million six hundred and thirty six thousand three hundred and forty two Euros (€7,851,636,342.00) and its registered office located at 12, Place des États-Unis, CS 70052, 92547 Montrouge Cedex,
France, registered under the n° Siren 304 187 701 at the Registre du Commerce et des Sociétés of Nanterre or any successor of it appointed under Clause 27 (The Security Trustee).
"Security Value" means the amount in Dollars (as certified by the Agent whose certificate shall, in the absence of manifest error, be conclusive and binding on the Borrower and the Agent) which, at any relevant time, is the aggregate of (i) the charter free market value of the Ship as most recently determined in accordance with Clause 13.4 (Valuation of the Ship); and (ii) the market value of any additional security for the time being actually provided to the Agent pursuant to Clause 15 (Security Value Maintenance).
"Servicing Party" means the Agent or the Security Trustee.
"Shares Security Deed" means a Bermudian law document dated 12 April 2017, executed by the Shareholder in favour of the Security Trustee and creating security over the share capital in the Borrower in the agreed form.
"Shareholder" means NCL International Ltd., a Bermuda company with its registered office at Park Place 55, Par-la-Ville Road, Hamilton HM 11, Bermuda.
"Ship" means the passenger cruise ship currently designated with Hull No. [*] (as more particularly described in the Shipbuilding Contract) to be constructed under the Shipbuilding Contract and to be delivered to, and purchased by, the Borrower and registered in its name under an Approved Flag.
"Shipbuilding Contract" has the meaning given in Recital (FN).
"SIMEST" means Società Italiana per Le Imprese all'Estero - SIMEST Spa, which grants export subsidies in Italy under and according to the Italian Legislative Decree n. 143/98 and its amendments.
"Specified Time" means a day or time determined in accordance with the following:
(a) | if LIBOR is fixed, the Quotation Day as of 11:00 am London time; and |
(b) | in relation to a Reference Bank Rate calculated by reference to the available quotations in accordance with Clause 6.7 (Calculation of Reference Bank Rate), noon on the Quotation Day. |
"Subordinated Debt Security" has the meaning given in paragraph (b)(ii) of Clause 12.14 (Financial Indebtedness and subordination of indebtedness).
"Subsidiary" has the following meaning:
a company (S) is a subsidiary of another company (P) if:
(b) | P has direct or indirect control over a majority of the voting rights attaching to the issued shares of S; or |
(c) | P has the direct or indirect power to appoint or remove a majority of the directors of S; or |
(d) | P otherwise has the direct or indirect power to ensure that the affairs of S are conducted in accordance with the wishes of P, |
and any company of which S is a subsidiary is a parent company of S.
"Supplemental Pre-delivery Security" means a deed to be entered into pursuant to the June 2021 Amendment and Restatement Agreement between the Borrower and the Security Trustee, supplemental to the Pre-delivery Security, creating security over the Pre-delivery Contracts.
"Tax" means any tax, levy, impost, duty, assessment, fee, deduction or other charge or withholding of a similar nature imposed by any governmental authority (including any penalty or interest payable in connection with any failure to pay or any delay in paying any of the same).
"Total Commitments" means the aggregate of the Total Tranche A Commitments, the Total Tranche B Commitments and the Total Tranche C Commitments.
(a) | actual, constructive, compromised, agreed or arranged total loss of the Ship; |
(c) | any arrest, capture, seizure or detention of the Ship (including any hijacking or theft) unless it is within 1 month redelivered to the Borrower's full control. |
(a) | in the case of an actual loss of the Ship, the date on which it occurred or, if that is unknown, the date when the Ship was last heard of; |
(b) | in the case of a constructive, compromised, agreed or arranged total loss of the Ship, the earliest of: |
(i) | the date on which a notice of abandonment is given to the insurers; and |
(ii) | the date of any compromise, arrangement or agreement made by or on behalf of the Borrower with the Ship's insurers in which the insurers agree to treat the Ship as a total loss; and |
"Total Tranche A Commitments" means the aggregate of the Tranche A Commitments, being eight hundred and sixty-eight million, one hundred eight thousand, one hundred eight Dollars and eleven Cent ($868,108,108.11) as at the date of the Original Facility Agreement.
"Total Tranche B Commitments" means the aggregate of the Tranche B Commitments, being two hundred fifty-eight million, seven hundred forty-four thousand, four hundred forty-four Dollars and forty-four Cent ($258,744,444.44) as at the date of this Agreement.
"Total Tranche C Commitments" means the aggregate of the Tranche C Commitments, being nineteen million, six hundred twenty-four thousand, eleven Dollars and nine Cent ($19,624,011.09) as at the date of this Agreement.
"Tranche" means Tranche A, Tranche B or Tranche C.
"Tranche A" means the part of the Facility made or to be made available by the Tranche A Lenders to the Borrower to finance (i) up to the Eligible Amount, the Dollar Equivalent of six hundred and forty million Euros (€640,000,000.00), corresponding to all or part of eighty per cent. (80%) of the Final Contract Price, (ii) the First Instalment of the SACE Premium and (iii) the Second Instalment of the SACE Premium.
"Tranche A Commitments" means, in relation to a Tranche A Lender, the amount set opposite its name under the heading "Tranche A Lenders" in Part A of Schedule 1 (Lenders and Commitments) and the amount of any other Tranche A Commitment transferred to it under this Agreement, to the extent not cancelled, reduced, terminated or transferred by it under this Agreement.
"Tranche A Lender" means a bank, financial institution, trust, fund or other entity listed in Part A of Schedule 1 (Lenders and Commitments) and acting through its Facility Office or its transferee, successor or assign.
"Tranche B" means the part of the Facility to be made available by the Tranche B Lenders to the Borrower to finance:
up to the Upsize Allowance Eligible Amount, the Dollar Equivalent of Euros one hundred eighty-five million six hundred thousand (€185,600,000), corresponding to all or part of eighty per cent. (80%) of the Upsize Allowance Price; and |
100% of the Tranche B Premium to be paid in accordance with paragraph (a) of Clause 8.6 (Tranche Premium). |
"Tranche B Commitments" means, in relation to a Tranche B Lender, the amount set opposite its name under the heading "Tranche B Lenders" in Part B of Schedule 1 (Lenders and Commitments) and the amount of any other Tranche B Commitment transferred to it under this Agreement, to the extent not cancelled, reduced, terminated or transferred by it under this Agreement.
"Tranche B Lender" means a bank, financial institution, trust, fund or other entity listed in Part B of Schedule 1 (Lenders and Commitments) and acting through its Facility Office or its transferee, successor or assign.
"Tranche B Premium" has the meaning given to this term in paragraph (a) of Clause 8.6 (Tranche B Premium).
"Tranche C" means the part of the Facility to be made available by the Tranche C Lenders to the Borrower to finance, if applicable, the second instalment of the Additional SACE Premium, calculated in accordance with paragraph (a)(ii) of Clause 8.5 (Additional Premium).
"Tranche C Commitments" means, in relation to a Tranche C Lender, the amount set opposite its name under the heading "Tranche C Lenders" in Part C of Schedule 1 (Lenders and Commitments) and the amount of any other Tranche C Commitment transferred to it under this Agreement, to the extent not cancelled, reduced, terminated or transferred by it under this Agreement.
"Tranche C Lender" means a bank, financial institution, trust, fund or other entity listed in Part C of Schedule 1 (Lenders and Commitments) and acting through its Facility Office or its transferee, successor or assign.
"Transaction Documents" means the Finance Documents and the Underlying Documents.
"Transfer Certificate" means a certificate substantially in the form set out in Schedule 4 (Form of Transfer Certificate) or any other form agreed between the Agent and the Borrower.
"UK Bail-In Legislation" means (to the extent that the United Kingdom is not an EEA Member Country which has implemented, or implements, Article 55 BRRD) Part 1 of the United Kingdom Banking Act 2009 and any other law or regulation applicable in the United Kingdom relating to the resolution of unsound or failing banks, investment firms or other financial institutes or their affiliates (otherwise than through liquidation, administration or other insolvency proceedings).
"Underlying Documents" means the Shipbuilding Contract, the Refund Guarantee, any Management Agreement, any bareboat charter and any charter and associated guarantee in respect of which a notice of assignment is required to be served under the terms of the General Assignment.
"Unpaid Sum" means (i) any sum due and payable but unpaid by an Obligor under the Finance Documents and (ii) any part of the Aggregate SACE Premium unpaid by the Borrower.
"Upsize Allowance" means an allowance in relation to:
the improvements, changes and modifications agreed between the Borrower (as Owner under the Shipbuilding Contract) and the Builder, pursuant to article 9.2 of the Shipbuilding Contract. |
"Upsize Allowance Eligible Amount" means eighty per cent. (80%) of the Dollar Equivalent of the Upsize Allowance Price.
"Upsize Allowance Price" means the price for the Upsize Allowance, in an amount of two hundred and thirty-two million Euros (€232,000,000).
(a) | any tax imposed in compliance with the Council Directive of 28 November 2006 on the common system of value added tax (EC Directive 2006/112); and |
"Write-down and Conversion Powers" means:
(b) |
(ii) | any similar or analogous powers under that Bail-In Legislation; and |
(c) |
(ii) | any similar or analogous powers under that UK Bail-In Legislation. |
1.2 |
In this Agreement:
"Agent", the "SACE Agent", the "Joint Mandated Lead Arranger", the "Security Trustee", any "Creditor Party", any "Secured Party", any "Lender", any "Tranche A Lender", any "Tranche B Lender", any "Tranche C Lender", any "Obligor" or any other "person", shall be construed so as to include its successors in title, permitted assigns and permitted transferees.
"approved by the Lenders" (or any similar determination or instruction by the Lenders) means approved in writing by the Agent acting on the instructions of all the Lenders and SACE (on such conditions as they may respectively impose) (or the Lenders only to the extent the SACE Insurance Policy does not cover the event for which such instruction or approval is required) and any requirement for approval by all the Lenders shall mean prior approval.
"approved by the Majority Lenders" (or any similar determination or instruction by the Majority Lenders) means approved in writing by the Agent acting on the instructions of the Majority Lenders and SACE (or the Majority Lenders only to the extent the SACE Insurance Policy does not cover the event for which such instruction or approval is required) (on such conditions as they may respectively impose) and otherwise approved means approved in writing by the Agent (on such conditions as the Agent may impose) and approval and approve shall be construed accordingly and any requirement for approval by the Agent or the Majority Lenders shall mean prior approval.
"asset" includes every kind of property, asset, interest or right, including any present, future or contingent right to any revenues or other payment.
"company" includes any partnership, joint venture and unincorporated association.
"consent" includes an authorisation, consent, approval, resolution, licence, exemption, filing, registration, notarisation and legalisation.
"contingent liability" means a liability which is not certain to arise and/or the amount of which remains unascertained.
"date of this Agreement" means _____ February_________ 2021.
"document" includes a deed; also a letter or electronic mail.
"expense" means any kind of cost, charge or expense (including all legal costs, charges and expenses) and any applicable Taxes including VAT.
"including" and "in particular" (and other similar expressions) shall be construed as not limiting any general words or expressions in connection with which they are used.
"indebtedness" includes any obligation (whether incurred as principal or as surety) for the payment or repayment of money, whether present or future, actual or contingent;
"law" includes any order or decree, any form of delegated legislation, any treaty or international convention and any regulation or resolution of the Council of the European Union, the European Commission, the United Nations or its Security Council.
"legal or administrative action" means any legal proceeding or arbitration and any administrative or regulatory action or investigation.
"liability" includes every kind of debt or liability (present or future, certain or contingent), whether incurred as principal or surety or otherwise.
"months" shall be construed in accordance with Clause 1.4 (Meaning of "month").
"parent company" has the meaning given in the definition of "Subsidiary".
"person" includes any individual, firm, company, corporation, government, any state, political sub-division of a state and local or municipal authority, agency of a state or any association, trust, joint venture, consortium or partnership; and any international organisation (whether or not having a separate legal personality).
"proceedings" means, in relation to any enforcement provision of a Finance Document, proceedings of any kind, including an application for a provisional or protective measure.
"regulation" includes any regulation, rule, official directive, request or guideline (whether or not having the force of law) of any governmental, intergovernmental or supranational body, agency, department or regulatory, self-regulatory or other authority or organisation.
1.3 |
"approved" means, for the purposes of Clause 14 (Insurance Undertakings), approved in writing by the Agent.
"excess risks" means the proportion of claims for general average, salvage and salvage charges not recoverable under the hull and machinery policies in respect of the Ship in consequence of its insured value being less than the value at which the Ship is assessed for the purpose of such claims.
"obligatory insurances" means all insurances effected, or which the Borrower is obliged to effect, under Clause 14 (Insurance Undertakings) or any other provision of this Agreement or another Finance Document.
"policy" in relation to any insurance, includes a slip, cover note, certificate of entry or other document evidencing the contract of insurance or its terms.
"protection and indemnity risks" means the usual risks covered by a protection and indemnity association managed in London, including pollution risks and the proportion (if any) of any sums payable to any other person or persons in case of collision which are not recoverable under the hull and machinery policies by reason of the incorporation in them of clause 6 of the International Hull Clauses (1/11/02) (1/11/03), clause 8 of the Institute Time Clauses (Hulls) (1/10/83) (1/11/95) or the Institute Amended Running Down Clause (1/10/71) or any equivalent provision.
"war risks" includes the risk of mines and all risks excluded by clause 29 of the International Hull Clauses (1/11/02 or 1/11/03), clause 24 of the Institute Time Clauses (Hulls) (1/11/95) or clause 23 of the Institute Time Clauses (Hulls)(1/10/83).
1.4 |
A period of one or more "months" ends on the day in the relevant calendar month numerically corresponding to the day of the calendar month on which the period started ("the numerically corresponding day"), but:
and "month" and "monthly" shall be construed accordingly.
1.5 | Non-applicable provisions between the Obligors and German Lenders |
The undertakings and covenants given under paragraph (d) of Clause 12.2 (Information), Clause 12.4 (Illicit Payments), Clause 12.5 (Prohibited Payments), Clause 12.25 (Compliance with laws etc.) or provisions contained in Clause 20.3 (Miscellaneous indemnities) or Clause 21.1 (Illegality and Sanctions) and the representations and warranties given under paragraphs (u), (v), (y), (z) and (jj) of Clause 11.2 (Continuing representations and warranties) and paragraph (j) of Clause 11.3 (Representations on the Delivery Date) respectively shall only be given, and be applicable to, a Lender incorporated in the Federal Republic of Germany insofar as the giving of and compliance with such undertakings and covenants and such representations and warranties do not result in a violation of or conflict with section 7 of the German Foreign Trade Regulation (Außenwirtschaftsverordnung) (in conjunction with section 4 paragraph 1 a no.3 foreign trade law (AWG) (Außenwirtschaftsgesetz)), any provision of Council Regulation (EC) 2271/1996 or any similar applicable anti-boycott law or regulation.
1.6 |
In this Agreement:
(d) | references to, or to a provision of, any law or regulation include any amendment, extension, re-enactment or replacement, whether made before the date of this Agreement or otherwise; |
(f) | words denoting the singular number shall include the plural and vice versa; and |
(g) | Clauses 1.1 (Definitions) to 1.6 (General Interpretation) apply unless the contrary intention appears. |
1.7 |
In interpreting a Finance Document or any provision of a Finance Document, all clauses, sub-clauses and other headings in that and any other Finance Document shall be entirely disregarded.
1.8 |
The schedules form an integral part of this Agreement.
2 |
2.1 |
Subject to the other provisions of this Agreement,:
in reimbursement to the Borrower or in payment to the Builder, up to the Eligible Amount, of all or part of eighty per cent. (80%) of the Final Contract Price; |
in reimbursement to the Borrower of the amount of the First Instalment of the SACE Premium paid by it to SACE in accordance with paragraph (a) of Clause 8.1 (SACE Premium); and |
in payment to SACE of the amount of the Second Instalment of the SACE Premium payable by the Borrower to SACE in accordance with paragraph (b) of Clause 8.1 (SACE Premium).; |
in reimbursement to the Borrower or in payment to the Builder (as set out in the relevant Drawdown Notice) up to the Upsize Allowance Eligible Amount, of all or part of eighty per cent. (80%) of the Upsize Allowance Price; and |
in reimbursement to the Borrower or in payment to SACE of the amount of the Tranche B Premium payable by the Borrower to SACE in accordance with paragraph (a)(i) of Clause 8.6 (Tranche B Premium); |
in payment to SACE of the amount of the Tranche B Premium payable by the Borrower to SACE in accordance with paragraph (a)(ii) of Clause 8.6 (Tranche B Premium). |
which may be payable by the Borrower to SACE in accordance with paragraph (a)(ii) of Clause 8.5 (Additional Premium).
2.2 |
Subject to the other provisions of this Agreement,:
each Tranche A Lender shall participate in each Advance under Tranche A in the proportion which, as at the relevant Drawdown Date, its Tranche A Commitment bears to the Total Tranche A Commitments; |
each Tranche C Lender shall participate in the Advance under Tranche C in the proportion which, as at the relevant Drawdown Date, its Tranche C Commitment bears to the Total Tranche C Commitments. |
2.3 |
The Borrower undertakes with each Secured Party to use each Advance only to pay for:
goods and services of Italian origin incorporated in the design, construction or delivery of the Ship; |
reimbursement to the Borrower of all or part of eighty per cent. (80%) of the First Shipbuilding Contract Instalment; |
reimbursement to the Borrower of the First Instalment of the SACE Premium paid by the Borrower direct to SACE in accordance with paragraph (a) of Clause 8.1 (SACE Premium); and |
the Second Instalment of the SACE Premium payable in accordance with paragraph (b) of Clause 8.1 (SACE Premium).; |
for goods and services in relation to the Upsize Allowance; and |
provided that the first Advance under Tranche B shall also be used to pay 100% of the Tranche B Premium, payable in accordance with paragraph (a) of Clause 8.6 (Tranche B Premium); and
the Advance under Tranche C only to pay for the second instalment of the Additional SACE Premium which may be payable in accordance with paragraph (a)(ii) of Clause 8.5 (Additional Premium). |
2.4 |
(c) | A Creditor Party and SACE may not, except as otherwise stated in the Finance Documents, separately enforce its rights under the Finance Documents. |
2.5 |
No Creditor Party is bound to monitor or verify the application of any amount borrowed pursuant to this Agreement.
2.6 |
The obligations of the Lenders under this Agreement are several; and a failure of a Lender to perform its obligations under this Agreement shall not result in:
(a) |
(b) | any Obligor or any other Lender being discharged (in whole or in part) from its obligations under any Finance Document, |
and in no circumstances shall a Lender have any responsibility for a failure of another Lender to perform its obligations under this Agreement or any other Finance Document.
3 |
3.1 |
The Borrower may only draw an Advance under a Tranche when the following conditions have been fulfilled to the satisfaction of the Agent and provided no Event of Default shall have
occurred and remains unremedied or is likely to occur as a consequence of the drawing of the Advance:
3.2 |
The Agent shall have received no later than the date of the Original Facility Agreement:
(i) | the Bermudian Obligors have been duly formed and are validly existing as companies under the laws of Bermuda; |
(ii) | the Finance Documents to which each Bermudian Obligor is a party to fall within the scope of the Bermudian Obligors' purpose as defined by their Memoranda of Association and By-laws; |
(iii) | each Bermudian Obligor's representatives were at the date of the Original Facility Agreement fully empowered to sign the Finance Documents to which it is a party; |
(v) | no withholding tax or stamp duty implications arise by virtue of the Bermudian Obligors entering into the Finance Documents to which they are a party respectively; |
(vii) | the Finance Documents to which each Bermudian Obligor is a party constitute the legal, valid and binding obligations of that Bermudian Obligor enforceable in accordance with its terms, |
and containing such qualifications and assumptions as are standard for opinions of this type;
(d) |
(g) | duly executed originals of the Original Guarantee and the Shares Security Deed and of each document to be submitted pursuant to it; |
(i) | payment of [*] per cent. ([*]%) of the Joint Mandated Lead Arranger structuring fee payable in accordance with paragraph (a)(i) of Clause 9 (Fees); |
(j) | payment of the initial portion of the Agent Structuring Fee (as defined in the Fee Letter), payable in accordance with terms of the Fee Letter; and |
(k) | an agreed form version of the Italian law tax opinion from legal counsel to the Creditor Parties in respect of the tax treatment of payments under the SACE Insurance Policy. |
3.3 | No later than forty-five (45) days before the first Drawdown Date under Tranche A |
The Agent shall have received from the Borrower no later than forty-five (45) days before the first Drawdown Date under Tranche A (and on each subsequent date on which a Compliance Certificate is to be received by the Security Trustee pursuant to clause 11.3(c) of the Original Guarantee) a duly completed Compliance Certificate from the Guarantor.
3.4 | No later than [*] days before the first Drawdown Date under Tranche A |
The Agent shall have received from the Borrower no later than [*] days before the first Drawdown Date under Tranche A:
(c) | a certified true copy bank statement evidencing receipt by the Builder of the First Shipbuilding Contract Instalment (as described in Recital (B)). |
3.5 | No later than five (5) Business Days before each Drawdown Date under any Tranche |
The Agent shall have received no later than five (5) Business Days before each Drawdown Date under any Tranche a Drawdown Notice from the Borrower, signed by a duly authorised signatory of the Borrower, specifying the amount of the Advance to be drawn down.
3.6 | No later than five (5) Business Days before the First Drawdown Date under Tranche A |
The Agent shall have received no later than five (5) Business Days before the first Drawdown Date under Tranche A:
(a) | an agreed form version of the Pre-delivery Security and of each document to be issued pursuant to it; |
(d) |
(e) |
(f) | an agreed form version of the Interest Make-Up Agreement relative to the Loan; |
(h) | if applicable, an agreed form version of the Subordinated Debt Security; and |
3.7 |
The Agent shall have received no later than the first Drawdown Date under Tranche A:
(a) | a duly executed original of the Pre-delivery Security (excluding any Account Pledge) and of each document to be issued pursuant to it; |
(d) | an original of the Interest Make-Up Agreement relative to the Loan and in full force and effect; |
(f) | an Italian law tax opinion from legal counsel to the Creditor Parties in respect of the tax treatment of payments under the SACE Insurance Policy. |
The Agent shall have received, no later than the first Drawdown Date under Tranche B:
a duly executed original of the Supplemental Pre-delivery Security and of each document to be issued pursuant to it; |
a duly executed original of the relevant addendum to the Interest Make-Up Agreement; |
a duly executed original of the relevant addendum to the SACE Insurance Policy; |
a copy of the Seventh Addendum and any other relevant addendum to the Shipbuilding Contract; |
A legal opinion of Watson Farley & Williams LLP, legal advisers to the Agent (acting on behalf of the Lenders) and SACE in Italy, substantially in the form and substance satisfactory to the Lenders. |
No later than the Drawdown Date in respect of each Advance under Tranche A other than first Advance under Tranche A and the Delivery Advance under Tranche A |
The Agent shall have received no later than the Drawdown Date in respect of each Advance under Tranche A other than in respect of the first Advance under Tranche A and the Delivery Advance under Tranche A, a copy of the class milestone certificate in respect of the instalment due under the Shipbuilding Contract to which the Advance relates issued by the classification society.
No later than the Drawdown Date in respect of each Advance under Tranche A and Tranche B other than the Delivery Advance under Tranche A and Tranche B |
The Agent shall have received no later than the Drawdown Date in respect of each Advance under Tranche A and Tranche B, other than the Delivery Advance under Tranche A and Tranche B:
as regards any previous Advance, in the event the Refund Guarantee issued in respect of such previous Advance cannot be renewed or extended: |
evidence that an Acceptable Deposit has accordingly been transferred to the Account pursuant to the terms of the Shipbuilding Contract; and |
a copy of the relevant invoice from the Builder in respect of the instalment under the Shipbuilding Contract to which the Advance relates; |
from the Borrower an amount equal to twenty per cent. (20%) of the relevant instalment due under the Shipbuilding Contract to which the Advance relates;
the Shipbuilding Contract continues to be in full force and effect; and, |
no default or mandatory prepayment event pursuant to Clause 16 (Cancellation, Prepayment and Mandatory Prepayment) is continuing or would result from the proposed Advance; |
if applicable, a duly executed original of the Subordinated Debt Security; and |
3.103.11No later than four (4) years before the Intended Delivery Date
The Agent shall have received no later than four (4) years before the Intended Delivery Date, payment of the remaining [*] per cent. ([*]%) of the Joint Mandated Lead Arranger structuring fee payable in accordance with paragraph (a)(ii) of Clause 9 (Fees).
3.113.12No later than ninety (90) days before the Intended Delivery Date
The Agent shall have received no later than ninety (90) days before the Intended Delivery Date:
(a) | notification from the Borrower of its chosen Maritime Registry; and |
(b) |
3.123.13No later than sixty (60) days before the Intended Delivery Date
The Agent shall have received from the Borrower no later than sixty (60) days before the Intended Delivery Date:
(a) |
(b) | a notice from the Borrower as described in paragraph (a) of Clause 8.4 (Refund) and in paragraph (f) of Clause 8.6 (Tranche B Premium); and |
3.133.14No later than fifteen (15) Business Days before the Intended Delivery Date
The Agent shall have received no later than fifteen (15) Business Days before the Intended Delivery Date insurance documents in form and substance satisfactory to the Lenders confirming that the Insurances have been effected and will be in full force and effect on the Delivery Date.
3.143.15No later than five (5) Business Days before the Intended Delivery Date
The Agent shall have received no later than five (5) Business Days before the Intended Delivery Date:
(b) | a final confirmation of the Intended Delivery Date signed by a duly authorised signatory of the Borrower, and counter-signed by a duly authorised signatory of the Builder. |
3.153.16No later than the Delivery Date
In respect of the Advance to be made available by the Tranche A Lenders on the Delivery Date, the Agent shall have received no later than the Delivery Date: |
if applicable, a duly executed original of the Subordinated Debt Security; |
evidence of payment to and receipt by the Builder of any other part of the Final Contract Price as at the Delivery Date not being financed hereunder; |
payment of the remaining portion of the Agent Structuring Fee (as defined in the Fee Letter), payable in accordance with terms of the Fee Letter; |
evidence of payment of all amounts which are due and payable hereunder by the Borrower on or prior to the Delivery Date; |
the Shipbuilding Contract continues to be in full force and effect; |
no default or mandatory prepayment event pursuant to Clause 16 (Cancellation, Prepayment and Mandatory Prepayment) is continuing or would result from the Delivery AdvanceAdvances; |
the repeating representations as set out in Clause 11 (Representations and Warranties) are true; and |
the representations to be made on the Delivery Date pursuant to paragraph (b) of Clause 1111.3 (Representations and Warrantieson the Delivery Date) are true; |
In respect of the Advance to be made available by the Tranche B Lenders on Delivery Date, the Agent shall have received no later than the Delivery Date: |
a copy of the relevant invoice from the Builder in respect of the Upsize Allowance to which such Advance relates; |
the documents, evidence or confirmations, as relevant, set out in paragraphs (a)(i), (a)(v), (a)(vi), (a)(vii) and (a)(viii) of this Clause 3.16 (No later than the Delivery Date) and |
evidence of payment to and receipt by the Builder of any other part of the Upsize Allowance Price as at the Delivery Date not being financed hereunder; |
provided always that, in relation to paragraphs (a), (b) and (c) above, the obligations of the relevant Lenders to make thesuch Advance under each of Tranche A, Tranche B and Tranche C, as applicable, available on the Delivery Date are subject to the Lenders remaining satisfied that each of the SACE Insurance Policy and the Interest Make-Up Agreement will cover the Loan following the advance of the Delivery Advancesuch Advances and delivery to the Agent of the documents listed in Schedule 3 (Documents to be produced by the Builder to the Agent on Delivery).
Immediately prior to the delivery of the Ship by the Builder to the Borrower, the Agent shall have received:
(a) |
(i) | the Ship will be registered in the name of the Borrower in the Maritime Registry; |
(g) | a confirmation from Hannaford Turner LLP, currently of 9 Cloak Lane107 Cheapside, London EC4R 2RU, UK, EC2V 6DN, (or any replacement process agent satisfactory to the Agent acting |
reasonably) that it will act for each of the relevant Obligors as agent for service of process in England in respect of the deed of covenants constituting part of the Mortgage (if applicable), the General Assignment and the Post-Delivery Assignment.
3.173.18Immediately following Delivery
Immediately following the delivery of the Ship by the Builder to the Borrower, the Agent shall receive:
(a) |
(b) | an opinion from legal counsel acceptable to the Secured Parties as to the law of the Maritime Registry in form and substance satisfactory to the Agent and the Secured Parties confirming: |
(i) | the valid registration of the Ship in the Maritime Registry; and |
(ii) | the Mortgage over the Ship is a first priority security and has been validly registered in the Maritime Registry; |
(e) | the documents listed in Schedule 3 (Documents to be produced by the Builder to the Agent on Delivery). |
3.183.19Notification of satisfaction of conditions precedent
The Agent shall notify the Tranche A Lenders and SACE, the Tranche B Lenders, the Tranche C Lenders, SACE and SIMEST, as applicable, promptly upon being satisfied as to the satisfaction of the conditions precedent referred to in this Clause 3 (Conditions Precedent).
3.193.20Waiver of conditions precedent
If the Majority Lenders, at their discretion, subject to the prior written consent of SACE, permit an Advance under a Tranche to be borrowed before any of the conditions precedent referred to in Clause 3 (Conditions Precedent) has been satisfied, the Borrower shall ensure that that condition is satisfied within five (5) Business Days after the date (as specified in the relevant part of Clause 3 (Conditions Precedent)) or such later date as the Agent may agree in writing with the Borrower.
3.203.21Changes to SACE's or SIMEST's requirements
(b) | If the Agent notifies the Borrower of any proposed changes to this Agreement under paragraph (a) above, and provided that: |
(i) | all the Lenders and the Borrower agree with such changes; and |
(ii) | the Borrower indemnifies and holds harmless the Agent and the Lenders for any reasonable costs that it may incur arising from or in connection with any such amendments (including legal fees), |
then such changes will be made to this Agreement in accordance with the terms hereof.
3.213.22No claim against the Creditor Parties
The Borrower agrees that the Creditor Parties may act on the instructions of the Italian Authorities in relation to this Agreement.
3.223.23Examination and reliance on documents by the Agent
parties thereto and collecting copies thereof (which copies shall be certified as true copies by an authorised signatory of the Builder and/or the Borrower, as applicable).
(e) | In case of any discrepancy in any such documents, the Agent shall notify the Borrower in writing thereof and shall request its approval of such discrepancy in writing. |
The Agent and the Lenders shall not be responsible for any delay in making available any Advances resulting from any requirement for the delivery of further information or documents reasonably required by the Agent for the relevant conditions precedent in this Agreement to be satisfied.
4 |
4.1 |
The Tranche B Lenders shall not be obliged to fulfil their obligation to make an Advance available under Tranche B other than: |
by reimbursing the Borrower or by paying the Builder (as set out in the relevant Drawdown Notice) all or part of eighty per cent. (80%) of the Upsize Allowance Price on behalf of and in the name of the Borrower; and |
by reimbursing to the Borrower or by paying SACE, as applicable, the amount of the Tranche B Premium referred to in paragraph (a)(i) of Clause 8.6 (Tranche B Premium); and |
by paying SACE the amount of the Tranche B Premium referred to in paragraph (a)(ii) of Clause 8.6 (Tranche B Premium), |
such amounts of the Tranche B Premium to be paid by the Borrower to SACE in accordance with paragraph (a) of Clause 8.6 (Tranche B Premium).
The Borrower hereby instructs the Tranche A Lenders in accordance with this Clause 4.1 (Borrower's irrevocable payment instructions) and in accordance with Schedule 6 (Drawdown ScheduleSchedules): |
The Borrower hereby instructs the Tranche B Lenders in accordance with this Clause 4.1 (Borrower's irrevocable payment instructions) and in accordance with Schedule 6 (Drawdown Schedules) to: |
reimburse to the Borrower or pay to the Builder in accordance with the relevant Drawdown Notice, up to the Upsize Allowance Eligible Amount, all or part of eighty per cent. (80%) of the Upsize Allowance Price in four (4) Advances in accordance with Schedule 6 (Drawdown Schedules); and |
pay to the Agent on behalf of the Tranche B Lenders: |
for reimbursement to the Borrower or for onward payment to SACE (such reimbursement to the Borrower or payment to SACE, as applicable, to be made for value on the first Drawdown Date under Tranche B), by drawing under this Agreement, the amount of the Tranche B Premium referred to in paragraph (a)(i) of Clause 8.6 (Tranche B Premium); and |
for onward payment to SACE (such payment to SACE to be made for value on the first Drawdown Date under Tranche B), by drawing under this Agreement, the amount of the Tranche B Premium referred to in paragraph (a)(ii) of Clause 8.6 (Tranche B Premium), |
such amounts of the Tranche B Premium to be paid by the Borrower to SACE pursuant to paragraph (a) of Clause 8.6 (Tranche B Premium).
Save as contemplated in Clause 4.3 (Modification of payment terms) below, the payment instruction contained in this Clause 4.1 (Borrower's irrevocable payment instructions) is irrevocable. |
4.2 |
The Dollar amounts to be drawn down under paragraph (aparagraphs (a), (b) and (c) of Clause 4.1 (Borrower's irrevocable payment instructions) shall be calculated by the Agent on the Conversion Rate Fixing Date in accordance with the definitions of "Eligible Amount", "Upsize Allowance Eligible Amount" and "Conversion Rate" in Clause 1.1 (Definitions).
4.3 |
The Borrower expressly acknowledges that the payment terms set out in this Clause may only be modified with the agreement of the Italian Authorities, the Agent, the Security Trustee, the Lenders and the Borrower in the case of paragraph (aparagraphs (d)(i) and (e)(i) of Clause 4.1 (Borrower's irrevocable payment instructions) and with the agreement of the Italian Authorities, the Agent, the Lenders and the Borrower in the case of paragraphs (bd)(ii), (d)(iii), (e)(ii) and (cf) of Clause 4.1 (Borrower's irrevocable payment instructions); provided that it is the intention of the Borrower, the Lenders, the Security Trustee and the Agent that prior to the Conversion Rate Fixing Date agreement shall be reached with those financial institutions with whom the Borrower has entered into the FOREX Contracts (the "Counterparties") in order
that the Euro payments due from the Counterparties under the FOREX Contracts shall be paid to the Agent for holding in escrow and to be released by the Agent simultaneously with (i) the payment of each Advance to the Builder denominated in Euro and (ii) the payment to the Counterparties of the Dollars due to them under the relevant FOREX Contracts out of the Dollar amount available under paragraph (ad)(i) and (e)(i) of Clause 4.1 (Borrower's irrevocable payment instructions), subject to the Borrower having deposited with the Agent before each Drawdown Date, if and to the extent required, any Dollar and/or Euro amounts as may be needed to ensure the payment in full of both the balance of the relevant Advance in Euro and the Dollars owed to the Counterparties under all the relevant FOREX Contracts.
4.4 |
(b) | Under this Agreement, there will be no more than five (5) Advances under this Agreement.: |
(c) | The amount of the first Advance under Tranche A shall not exceed the aggregate of (i) the Dollar Equivalent of 80% of the First Shipbuilding Contract Instalment and (ii) the SACE Premium. |
The amount of each Advance under Tranche B (save for the first Advance under Tranche B) shall not exceed the Dollar Equivalent of eighty per cent. (80%) of the amount of the instalment due to the Builder under the Shipbuilding Contract to which that Advance relates. |
the Tranche A Advances cannot exceed the Total Tranche A Commitments; |
the Tranche B Advances cannot exceed the Total Tranche B Commitments; |
the Tranche C Advance cannot exceed the Total Tranche C Commitments; and |
the aggregate amount of the Advances under all Tranches cannot exceed the Maximum Loan AmountTotal Commitments. |
The Lenders shall not be under any obligation to lend any Advance to the Borrower if prior to that Advance any of the events specified in Article 20.2 of the Shipbuilding Contract occurs. |
4.5 |
The Agent shall promptly notify the Tranche A Lenders, the Tranche B Lenders and the Tranche C Lenders, as applicable, that it has received a Drawdown Notice in relation to a Tranche and shall inform each relevant Lender of:
(a) |
(b) | the amount of that Lender's participation in the Advance; and |
(c) |
4.6 |
Subject to the provisions of this Agreement, each Lender shall, on and with value on each Drawdown Date under a Tranche, make available to the Agent the amount due from that Lender under Clause 2.2 (Lenders' participations in Loan) on that Drawdown Date.
4.7 |
Subject to the provisions of this Agreement, the Agent shall on each Drawdown Date pay the amounts which the Agent receives from the Lenders under Clause 4.6 (Lenders to make available Contributions) in the like funds as the Agent received the payments from the Lenders:
(b) | in the case of an amount referred to in paragraph (bd)(ii) of Clause 4.1 (Borrower's irrevocable payment instructions) to the account of the Borrower which the Borrower shall specify; and |
in the case of an amount referred to in paragraph (d)(iii) of Clause 4.1 (Borrower's irrevocable payment instructions) to the account of SACE which the SACE Agent shall specify; |
in the case of an amount referred to in paragraph (e)(ii)(A) of Clause 4.1 (Borrower's irrevocable payment instructions) to the account of the Borrower which the Borrower specifies in the Drawdown Notice or SACE which the SACE Agent shall specify; |
in the case of an amount referred to in paragraph (e)(ii)(B) of Clause 4.1 (Borrower's irrevocable payment instructions) to the account of SACE which the SACE Agent shall specify; and |
in the case of an amount referred to in paragraph (cf) of Clause 4.1 (Borrower's irrevocable payment instructions) to the account of SACE which the SACE Agent shall specify. |
4.8 |
The payment by the Agent under Clause 4.7 (Disbursement of Advance) shall constitute the making of the Advance and the Borrower shall at that time become indebted, as principal and direct obligor, to each relevant Lender in an amount equal to that Lender's ContributionContributions.
5 |
5.1 |
The Borrower shall repay the Loan by twenty-four (24) consecutive six-monthly instalments from the earlier of (i) the Delivery Date and (ii) the date of actual disbursement of the respective delivery instalment (the "Starting Point of Repayment").
5.2 |
The first repayment instalment shall be repaid on the date falling six (6) months after the Starting Point of Repayment and the last repayment instalment on the date falling one hundred and forty-four (144) months after the Starting Point of Repayment, each date of payment of an instalment being a "Repayment Date".
5.3 |
Each repayment instalment of the Loan shall be of an equal amount.
5.4 |
On the final Repayment Date, the Borrower shall additionally pay to the Agent for the account of the Creditor Parties all other sums then accrued or owing under any Finance Document.
6 |
6.1 |
The Borrower shall provide notification, signed by a duly authorised signatory of the Borrower, to the Agent at least [*] days before the first Drawdown Date under Tranche A specifying which of the Fixed Interest Rate or the Floating Interest Rate shall be applicable to all Advances until the date of payment of the final repayment instalment of the Loan.
6.2 |
If the Borrower has specified a Fixed Interest Rate pursuant to Clause 6.1 (Fixed or Floating Interest Rate), the Loan shall bear interest in respect of each Interest Period at the Fixed Interest Rate. Such interest shall accrue on the actual number of days elapsed based upon a 360 day year and shall be paid on the last day of each Interest Period.
6.3 |
If:
(a) | the Borrower has specified a Floating Interest Rate pursuant to Clause 6.1 (Fixed or Floating Interest Rate); or |
(d) | SIMEST has failed to make a net payment of interest to the Lenders pursuant to the Interest Make-Up Agreement, |
the rate of interest on the Loan in respect of any Interest Period shall be the Floating Interest Rate applicable for that Interest Period and the following provisions of this Clause 6 (Interest) shall apply (in the case of the circumstances referred to in paragraph (b) above, with effect from the date on which the Interest Make-Up Agreement ceases to be in effect, with such consequential amendments as shall be necessary to give effect to the switch from a Fixed Interest Rate to a Floating Interest Rate).
6.4 |
Subject to the provisions of this Agreement, interest on the Loan, as applicable, in respect of each Interest Period shall accrue on the actual number of days elapsed based upon a 360 day year and shall be paid by the Borrower on the last day of that Interest Period.
6.5 |
The Agent shall notify the Borrower and each relevant Lender of each Floating Interest Rate and the duration of each Interest Period as soon as reasonably practicable after each is determined and no later than the Quotation Day.
6.6 |
(b) | Reference Bank Rate: If no Screen Rate is available for LIBOR for: |
(i) |
(ii) | the Interest Period of the Loan or any part of the Loan and it is not possible to calculate the Interpolated Screen Rate, |
the applicable LIBOR shall be the Reference Bank Rate as of the Specified Time and for a period equal in length to the Interest Period of the Loan or that part of the Loan.